Downloads
Overview Search Downloads Submit file Up
Download details
P/066/2023- Shri Greenol K.B.
The appellant sri. Greenol K.B. is a consumer of the licensee under the Kalady Electrical Section. The appellant availed power connection for his residential apartment in the high rise building named “Atlas Celestial Park” at Nedumbassery, Ernakulam District. The appellant had applied for a LT 1A domestic service connection in September 2023 along with wiring test cum completion certificate. There are 208 individual flats in this high rise building. The initial scheme approval from the Electrical Inspectorate has obtained showing the electrical scheme of all flats. The test cum completion certificate attached by the appellant was signed by the contractor other than the contractor who obtained the scheme approval. There was an HT connection for feeding the power to some of the flats in the commercial tariff. The flat owners went to court for obtaining the individual LT connection. The Hon’ble High Court of division bench have ordered for giving individual LT connection by disconnecting and dismantling the HT connection on January 2021. The appellant obtained the inspectorate approval on 27/09/2023. The application complying with that of the regulation has submitted on 01/12/2023 and the power supply was connected on 04/12/2023. The appellant filed petition to the CGRF requesting for an early service connection and compensation for the delay and also action against all those who are involved & delay the connection. The CGRF issued order dated 24/11/2023 stating that the respondent have to provide electricity connection on submitting the energization approval from the Electrical Inspectorate. Aggrieved by the decision of CGRF, the appeal petition is filed to this authority.

Data
Size 152.32 KB
Downloads 457
Created 2024-03-18 06:33:41

Download
Back

Contact Us

KERALA ELECTRICITY OMBUDSMAN
D.H. Road & Foreshore Road Junction,
Near Gandhi Square,
Ernakulam, Kerala-682 016
Ph: 0484 2346488, Mob: 8714356488

Any Queries?

Send an email to info@keralaeo.org

Do you Know?

Consumers should submit  petitions to CGRF first before appealing Ombudsman.

Visitors Counter

mod_vvisit_counterToday5828
mod_vvisit_counterAll5478241